Terms and Conditions

1. Introduction

These Terms and Conditions ("Terms") govern the agreement between Brand Interior the Company and the client, Client for the provision of interior design services for residential and/or commercial properties. By engaging our services, the Client agrees to comply with these Terms.

2. Scope of Services

• Space planning and layout design
• Furniture and decor selection
• Material and finish recommendations
• Custom design solutions
• Project management and supervision

Changes to the agreed scope may incur additional costs and timelines.

3. Client Responsibilities

• Provide accurate information regarding the project requirements and preferences.
• Grant access to the property for site visits, measurements, and installations.
• Ensure timely payments as per the agreed schedule.
• Obtain necessary permissions and approvals for any structural modifications.

4. Fees and Payment Terms

The project cost and payment schedule will be outlined in the proposal.

• An initial deposit of [Percentage]% is required to confirm the project.
• Payments are due as per the milestones specified in the agreement.
• Late payments may result in project delays and/or additional fees.

5. Timeline

Project timelines are estimates and may be affected by unforeseen circumstances, including but not limited to material availability, vendor delays, or force majeure events. The Company will communicate any changes to the timeline promptly.

6. Changes and Revisions

Any changes to the approved design or scope of work must be requested in writing. Additional fees may apply for revisions beyond the initial agreed design.

7. Cancellations and Refunds

The Client may cancel the project by providing written notice. Refunds will be issued only for work not yet performed, minus a cancellation fee of [Specify Amount or Percentage]. Non-refundable deposits and costs incurred for materials or third-party services will not be reimbursed.

8. Warranties and Liabilities

• The Company warrants that services will be performed with reasonable skill and care.
• The Company is not liable for defects or delays caused by third-party vendors, contractors, or suppliers.
• The Client assumes responsibility for ensuring the structural integrity of the property for any modifications.

9. Intellectual Property

All design concepts, drawings, and materials provided by the Company remain its intellectual property unless otherwise agreed in writing. The Client may not replicate or use the designs for purposes other than the agreed project.

10. Confidentiality

Both parties agree to keep all project-related information confidential unless required for execution or with prior consent.

11. Dispute Resolution

Any disputes will be resolved through negotiation in good faith. If unresolved, disputes may be referred to mediation or arbitration in accordance with local laws.

12. Governing Law

These Terms are governed by the laws of [Specify Jurisdiction].

13. Force Majeure

The Company will not be held liable for delays or non-performance due to circumstances beyond its control, including natural disasters, labor strikes, or governmental restrictions.

14. Termination

Either party may terminate the agreement with written notice if the other party breaches the Terms. Upon termination, the Client will pay for services rendered up to the termination date.

15. Entire Agreement

These Terms, along with the signed proposal and any other written agreements, constitute the entire agreement between the parties and supersede any prior communications.